Legals for April, 9 2020

NOTICE INVITING BIDS OWNER: Boundary County 6452 Kootenai Street Bonners Ferry, Idaho 83805 Separate sealed BIDS for the: Boundary County Airport Snow Removal Equipment Building FAA/AIP Project No. 3-16-0004-016-2019 Will be received by Owner at the office of the Boundary County Board of Commissioners, 6452 Kootenai Street, Bonners Ferry, Idaho until 2:00 p.m., Monday April 20, 2020. Mailed bids shall be submitted to P.O. Box 419, Bonners Ferry, Idaho 83805. Bids will be publicly opened in and read aloud. It shall be the duty of each Bidder to submit his/her bid on or before the hour and date specified. Work associated with proposed improvements are generally described as follows: Snow removal equipment building consists of all elements necessary to construct a pre-engineered wood frame or metal building for storage of the airport's snow removal equipment. Other items include associated excavation, embankment, site grading, concrete approach, electrical, mechanical and site work for building construction. Interested bidders may obtain bid documents at www.to-engineersplanroom.com. Electronic documents in PDF format may be downloaded at no cost. Bidders must register at www.to-engineersplanroom.com to be placed on the planholders list and automatically receive addenda. Bid documents may be ordered in hard copy format for purchase at cost (nonrefundable). Questions should be directed to the Engineer Trey Dail (208) 762-3644 or adail@to-engineers.com. A Bid Guaranty, payable in cash, by cashier's check, certified check or bid bond, of 5 percent of the BID AMOUNT is required. Separate Performance and Payment Bonds each in the amount of 100 percent of the CONTRACT AMOUNT will be required. Each bidder must supply all the information required by the Bid Documents and Specifications. All prospective bidders are directed to the Instructions for Bidders for discussion of Bid policies, procedures, and requirements. The Owner reserves the right to reject any and all Bids, to waive any and all informalities and to negotiate contract terms with the successful Bidder, and the right to disregard all non-conforming, non-responsive or conditional Bids. Boundary County, in accordance with the provisions of Title VI of the Civil Rights Act of 1964 (78 Stat. 252, 42 U.S.C. $9 2000d to 2000d-4) and the Regulations, hereby notifies all bidders that it will affirmatively ensure that any contract entered into pursuant to this advertisement, disadvantaged business enterprises will be afforded full and fair opportunity to submit bids in response to this invitation and will not be discriminated against on the grounds of race, color, or national origin in consideration for an award. Prospective Contractors are notified that the work under this Contract is funded in part by a grant from the Federal Aviation Administration and as such this solicitation and any resulting contract are subject to the requirements of the Buy America Preference; Civil Rights - Title VI Assurance; Davis Bacon; Debarment and Suspension; Disadvantage Business Enterprise; Foreign Trade Restriction; Lobby Federal Employee; and Recovered Materials contract provisions. The requirements of 49 CFR part 26 apply to this contract. It is the policy of Boundary County to practice nondiscrimination based on race, color, sex, or national origin in the award or performance of this contract. The Owner encourages participation by all firms qualifying under this solicitation regardless of business size or ownership. By submitting a bid/proposal under this solicitation, the bidder or offeror certifies that neither it nor its principals are presently debarred or suspended by any Federal department or agency from participation in this transaction. No contractor, subcontractor, or specialty contractor shall be required to have a current license as a Contractor in the State of Idaho in order to submit a bid or proposal on this project; prior to award and execution of the Contract, the successful bidder shall secure an Idaho Public Works Contractor's License. Notice of Requirement for Affirmative Action to ensure Equal Employment Opportunity: 1. The Offeror's or Bidder's attention is called to the "Equal Opportunity Clause" and the "Standard Federal Equal Employment Opportunity Construction Contract Specifications" set forth herein. 2. The goals and timetables for minority and female participation, expressed in percentage terms for the Contractor's aggregate workforce in each trade on all construction work in the covered area, are as follows: Goals for minority participation for each trade 3.0% Goals for female participation in each trade 6.9% These goals are applicable to all of the Contractor's construction work (whether or not it is Federal or federally assisted) performed in the covered area. If the Contractor performs construction work in a geographical area located outside of the covered area, it shall apply the goals established for such geographical area where the work is actually performed. With regard to this second area, the Contractor also is subject to the goals for both its federally involved and non-federally involved construction. The Contractor's compliance with the Executive Order and the regulations in 41 CFR Part 60-4 shall be based on its implementation of the Equal Opportunity Clause, specific affirmative action obligations required by the specifications set forth in 41 CFR 60-4.3(a) and its efforts to meet the goals. The hours of minority and female employment and training must be substantially uniform throughout the length of the contract, and in each trade, and the Contractor shall make a good faith effort to employ minorities and women evenly on each of its projects. The transfer of minority or female employees or trainees from Contractor to Contractor or from project to project for the sole purpose of meeting the Contractor's goals shall be a violation of the contract, the Executive Order and the regulations in 41 CFR Part 60-4. Compliance with the goals will be measured against the total work hours performed. 3. The Contractor shall provide written notification to the Director of the Office of Federal Contract Compliance Programs (OFCCP) within 10 working days of award of any construction subcontract in excess of $10,000 at any tier for construction work under the contract resulting from this solicitation. The notification shall list the name, address, and telephone number of the subcontractor; employer identification number of the subcontractor; estimated dollar amount of the subcontract; estimated starting and completion dates of the subcontract; and the geographical area in which the subcontract is to be performed. 4. As used in this notice and in the contract resulting from this solicitation, the "covered area" is the State of Idaho, Boundary County, and the City of Bonners Ferry. By: Boundary County, Idaho BFH#10378/AD#374740 APRIL 2, 9, 2020

NOTICE OF HEARING ON NAME CHANGE (Adult or Emancipated Minor) Case No. CV11.20.88 IN THE DISTRICT COURT FOR THE FIRST JUDICIAL DISTRICT FOR THE STATE OF IDAHO, IN AND FOR THE COUNTY OF BOUNDARY. IN RE: Debra Gayle Halcro A Petition to change the name of Debra Gayle Halcro, now residing in the city of Naples, State of Idaho, has been filed in the District Court in Boundary County, Idaho. The name will change to Debra Gayle Caballero. The reason for the change in name is: After living together 22 yrs and legally declared surviving spouse after his death would now like to carry his name. Joe J Caballero. A hearing on the petition is scheduled for 9:30 o´çlock a.m. on 4/28/2020 at the Boundary County Courthouse. Objections may be filed by any person who can show the court a good reason against the name change. Date: March 9, 2020 Glenda Poston Clerk of The District Court By: /s/ Jamie Wilson BFH LEGAL 10366 MARCH 19, 26, APRIL 2, 9, 2020

STATE TIMBER SALE CR200365, DUNE AGAIN OSR A public oral auction will be conducted at the Idaho Department of Lands office, 2550 Highway 2 W., Sandpoint, ID 83864, at 10:30 a.m. local time, on Tuesday, May 19, 2020 for an estimated 1,175 MBF of timber marked or otherwise designated for cutting. In addition, there is an unestimated volume of forest products that may be removed at the option of the purchaser. Prior to bidding, eligible bidders shall present a certified check or bank draft payable to Treasurer, State of Idaho, or a bid bond acceptable to the State, in the amount of $18,127.25 which is 10% of the appraised net sale value of $181,272.50. The successful bidder's deposit will be forfeited to the State should the bidder fail to complete the contract. The State will not accept bids from parties who are delinquent on payments on existing state contracts. The average starting minimum bid price is $155.43 per MBF. The sale is located within Section 11, Township 60N, Range 01W, B.M., Boundary County, State of Idaho. Sale duration is 2 years. The sale may include blowdown and/or insect and disease infected timber which may result in additional volume and recovery reductions. Interested purchasers should carefully examine the sale and make their own estimates as to volume recovery, surface conditions, and proposed construction prior to bidding on the sale. Additional information concerning the timber and conditions of sale is available to the public and interested bidders on the department's timber sale website at http://web.idl.idaho.gov/timbersale/Search.aspx or from the Idaho Department of Lands office, Sandpoint, Idaho. Please note purchaser insurance requirements posted on the timber sale website. The Department of Lands, as authorized by the State Board of Land Commissioners reserves the right to reject any and all bids provided that good and sufficient grounds for rejecting the bid shall be stated in the rejection notice and shall not be in violation of applicable law. If you are disabled and need some form of accommodation, please call (208) 263-5104 five days prior to the date of sale. For text telephone services, please call 1-800-377-3529. BFH LEGAL 10371 APRIL 9, 16, 23, 30, 2020

IN THE DISTRICT COURT OF THE FIRST JUDICIAL DISTRICT OF THE STATE OF IDAHO, IN AND FOR THE COUNTY OF BOUNDARY MAGISTRATE DIVISION IN THE MATTER OF THE ESTATE OF CASE NO. CV11- 20-0085 Dixie L. Whallon NOTICE TO CREDITORS (I.C. 15-3-801) Deceased. NOTICE IS HEREBY GIVEN that the undersigned has been appointed personal representative of the above-named decedent. All persons having claims against the decedent or the estate are required to present their claims within four months after the date of the first publication of this Notice or said claims will be forever barred. Claims must be presented to the undersigned at the address indicated, and filed with the Clerk of the Court. DATED this 19th day of March 2020. (s) Chris Whallon. 15012 E. Crown Ave. Spokane Valley, WA 99216. Telephone: 509-590-6102 BFH LEGAL 10373 MARCH 26, APRIL 2, 9, 2020

LEGAL NOTICE NOTICE TO CREDITORS CASE NO. CVCVI 1-20-0044 NOTICE IS HEREBY GIVEN, that Ted Stone has been appointed personal representative of the Estate of Christopher J. Stone, First Judicial District, Boundary County, ID. All persons having claims against the decedent or the estate are required to present their claims within four (4) months after the date of the first publication of this Notice or said claims shall be forever barred. Claims must be provided to attorney Robert Montgomery at 2160 S. Twin Rapid, Boise, ID.83709 and filed with the Clerk of the Court in Boundary County. Dated March 16, 2020 BFH LEGAL 10370 MARCH 26, APRIL 2, 9, 2020

NOTICE OF HEARING ON NAME CHANGE (Adult) CASE NO. CV11-20-0113 IN THE DISTRICT COURT OF THE FIRST JUDICIAL DISTRICT OF THE STATE OF IDAHO, IN AND FOR THE COUNTY OF BOUNDARY MAGISTRATE DIVISION IN RE: BRENDA BROOK HUGGINS, ALSO KNOWN AS BRENDA BROOK VANDER DOES, NOTICE OF HEARING BRENDA BROOK BILDERBACK, and ON BRENDA BROOK NYDA Petitioner. A Petition to change the name of BRENDA BROOK HUGGINS, also known as BRENDA BROOK VANDER DOES, BRENDA BROOK BILDERBACK and BRENDA BROOK NYDAM, now residing in the City of Bonners Ferry, State of Idaho, has been filed in the District Court in Boundary County, Idaho. The name will change to BRENDA BROOK HUGGINS. The reason for the change in name is: passport and driver license requirement. A hearing on the petition is scheduled for 9:30 o'clock a.m. on August 4, 2020 at the Boundary County Courthouse. Objections may be filed by any person who can show the court a good reason against the name change. DATED this 24th day of March 2020. GLENDA POSTON, CLERK OF THE DISTRICT COURT (s)Jamie Wilson, Deputy Clerk BFH LEGAL 10376 APRIL 2, 9, 16, 23, 2020

IN THE DISTRICT COURT OF THE FIRST JUDICIAL DISTRICT OF THE STATE OF IDAHO, IN AND FOR THE COUNTY OF BOUNDARY KATHLEEN D. COLLINS, Who acquired title as KATHLEEN D. BOYCE, an unmarried individual; Plaintiff, VS. THE ESTATE OF JAMES F. O'LEARY, deceased; and NICOLE O'LEARY, also known as NICOLE GASTON, the sole heir of the Estate of James F. O'Leary; Defendants. TO: THE ESTATE OF JAMES F. O'LEARY, deceased; and TO: NICOLE O'LEARY, also known as NICOLE GASTON: You have been sued by KATHLEEN D. COLLINS, Who acquired title as KATHLEEN D. BOYCE, the Plaintiff, in the District Court in and for Boundary County, Idaho, in the above-captioned case. The nature of the claim against you is to quiet title to that certain real property located in Boundary County, Idaho, and legally described as follows: A portion of the South east Quarter of the South west Quarter (SE1/4 SW1/4) of Section 25, Township 62 Range 2 East B.M., aka Ellis (SEI/4 Tract #30, described as fol lows: Commencing at the Northwest corner of the SE1/4 of the SW1/4, Section 25, Township 62 North, Range 2 East B.M., aka Ellis Tract #30, which is the true point of begin ning; thence Easter ly on the North line of the SE1/4 of the SW1/4, 1320 feet more or less to the Northeast comer of the SE1/4 of the SW1/4; thence Southerly on the East line 1320 feet, more or less, to the Southeast comer of the SE1/4 of the SW1/4; thence North westerly 1866 feet to the true point of beginning to the Northwest comer of the SE1/4 of the SW1/4; Any time after twenty-one (21) days following the last publication of this Summons By Publication, the Court may enter ajudgment against you Without further notice, unless prior to that time you have filed a written response in the proper form, including the Case Number, and paid any required filing fee to the Clerk of the Boundary County Court at 6452 Kootenai St. #22, Bonnets Ferry, ID 83805, or at PO Box 419, Bonners Ferry, ID 83805, telephone number (208) 267-5504, and served a copy of your response on the Plaintiffs' attorney, Brent G. Schlotthauer, P.O. Box 808, Coeur d'Alene, Idaho, 83816-0808, telephone number (208) 664-4457. A copy of the Publication Summons and Complaint for Quiet Title can be obtained by contacting either the Clerk of the Court or the attorney for Plaintiff. If you Wish legal assistance, you should immediately retain an attorney to advise you in this matter. DATED March 13, 2020 GLENDA POSTON CLERK OF THE DISTRICT COURT By: DEPUTY CLERK (s) Case NO. CV11-20-0096 PUBLICATION SUMMONS BFH LEGAL 10368 MARCH 26, APRIL 2, 9, 16, 2020